Terms and conditions

Electrical Wiring Disclaimer:

Zonaestilo is not liable for any inaccuracies  or any installation errors by the electrical contractor that result in property or motor damage. Additionally, owners of battery-operated window treatments are responsible for the regular charging and replacement of their battery units.

Installation Disclaimer:

Prior to any installation services provided by Zonaestilo, it is the responsibility of the purchaser to ensure that all valuables, furniture, and other items are removed from the work area. This ensures the safety of your belongings and facilitates a smoother installation process. Once installation is complete, the responsibility to replace these items rests with the purchaser. Zonaestilo is not liable for damage to any items not removed from the installation area.

Delivery Dates Disclaimer:

Please note that all delivery dates provided by Zonaestilo are estimates and depend on the timely arrival of necessary fabrics and equipment. While we strive to meet these estimates, there may be occasions when adjustments are necessary due to unforeseen circumstances. Zonaestilo is not liable for any expenses or costs arising as a result of such delivery delays.

Lien Rights:

According to Florida Statutes Chapter 713, Zonaestilo retains the right to file a lien against the property of a client for any outstanding payments. The property owner will be notified in advance of any lien action.


Legal Disclaimer:

In the event that an unpaid invoice requires legal intervention, ZonaEstilo is entitled to recover reasonable attorneys’ fees and court costs from the party at fault. All terms and conditions adhere to Florida State law. By engaging with Zonaestilo, the client agrees to the jurisdiction of the courts within Miami-Dade or Broward County, Florida, and relinquishes any right to object to the venue in these locations.

Disclaimer: Installation of Roller Shades and Drapes on Uneven Surfaces


ZonaEstilo acknowledges that installing roller shades and drapes on uneven surfaces poses certain risks and challenges. While we strive to provide quality installation services, we cannot guarantee the stability or perfect alignment of roller shades and drapes when mounted on uneven surfaces.